Last Updated: 4/16/2025

1. Introduction

Welcome to MSH Construction (referred to as “we,” “us,” or “our”). By visiting our website or engaging our construction services, you agree to be bound by the following Terms and Conditions. If you do not agree to these terms, please discontinue use of our website and services.

2. Services

• Scope of Work: MSH Construction provides general construction services in Palm Beach County, Florida. Specific details regarding scope, timelines, costs, and deliverables will be outlined in individual contracts or project proposals.

• Estimates and Proposals: All project proposals and cost estimates are valid for a specified period. We reserve the right to update proposals if the scope of work changes.

3. Payments

• Fees and Invoicing: Payment terms, schedules, and methods will be specified in the construction contract.

• Late Payments: Late payments may be subject to additional charges, interest, or work stoppage at our discretion.

4. Changes to Work

• Change Orders: Any modifications to the original scope of work must be documented as an approved change order, which may affect the project timeline and cost.

• Client Responsibilities: You agree to provide timely approvals and access to the worksite as needed to avoid delays.

5. Warranties and Liability

• Warranties: We adhere to industry standards and applicable building codes. Limited warranties on workmanship and materials may apply as specified in individual contracts.

• Liability: To the fullest extent permitted by law, MSH Construction is not liable for indirect, incidental, or consequential damages arising out of services provided.

6. Intellectual Property

All content on our website—including text, images, logos, and other materials—is the exclusive property of MSH Construction. Unauthorized use, reproduction, or distribution is prohibited.

7. Governing Law

These Terms and Conditions are governed by and construed in accordance with the laws of the State of Florida. Any disputes shall be resolved in the courts of Palm Beach County.

8. Changes to These Terms

MSH Construction reserves the right to update these Terms and Conditions at any time. Changes will be posted on our website with the “Last Updated” date revised accordingly.

9. Contact Us

If you have any questions or concerns about these Terms & Conditions, please contact us at:
Phone: 561-552-3611
Contact: Contact MSH
Address: 4937 S Lake Drive Boynton Beach, FL 33436